광주지방법원 | 2024-06-20 | 2021가합58917
법원 판례 기준으로 판결요지와 원문 출처를 내부에서 확인하세요.
원문이 아닌 정리본이며, 저장된 요약의 끝부분이 잘려 있을 수 있습니다.
건축공사 도급계약 해지 및 하자보수에 따른 부당이득, 지체상금, 손해배상 청구 사건
결과 요약
- 회사는 근로자에게 934,159,605원 및 이에 대한 지연손해금을 지급함.
- 근로자의 나머지 청구는 기각함.
- 소송비용은 근로자가 1/3, 회사가 2/3 부담하고, 보조참가로 인한 비용은 피고보조참가인이 부담함.
사실관계
- 근로자는 2020. 6. 24. 회사에게 '(주)A 공장 증축공사'를 도급하였고, 2020. 12. 4. 준공기한을 2020. 12. 20.로 연장하는 변경계약을 체결함.
- 회사는 2020. 10. 20. 피고보조참가인에게 이 사건 공사 중 판넬, 창호, 유리공사 부분을 하도급하였고, 피고보조참가인은 2020. 11. 5. 이 사건 샌드위치판넬 설치공사를 완료함.
- 근로자는 2021. 2. 15. 이후 회사에게 기성고 공사대금을 지급하지 않았고, 2021. 2.경 피고와 주요 공사대금을 하도급업체에 직접 지급하기로 합의함.
- 회사는 2021. 5.경까지 외부판넬 마감공사 등을 진행하다가 공사를 중단하였고, 근로자는 현재까지 신축 공장 건물에 대한 사용승인을 받지 못함.
- 근로자는 2021. 6. 7.경까지 피고 또는 하도급업체에 총 1,569,463,420원을 지급함.
핵심 쟁점, 법리 및 법원의 판단
이 사건 도급계약의 해지 여부 및 시점
- 법리: 쌍무계약에서 자동해제 약정이 있더라도, 당사자들이 계약이 유효함을 전제로 이행을 촉구하거나 급부를 수령하였다면 자동해제 약정의 효력을 상실시키고 계약을 부활시키기로 합의한 것으로 봄이 상당함. 이 경우 채무불이행을 이유로 한 해제권 행사는 별도의 최고를 요하지 않음.
- 판단:
- 원고와 회사는 이 사건 공사의 준공기한을 2020. 12. 20.로 정하였고, 공사계약 특수조건 제4조에 따라 준공기한 내 미준공 시 계약이 자동해지된다고 약정함.
- 그러나 근로자가 2021. 2.경 하도급업체에 직접 공사대금을 지급하기로 합의하고 2021. 5.경까지 공사가 진행된 점, 근로자가 2021. 3. 29. 및 2021. 4. 23. 회사에게 지체상금 지급을 요청하며 이행을 촉구한 점 등을 고려할 때, 자동해제 약정의 효력을 상실시키고 계약을 부활시키기로 합의한 것으로 봄이 상당함.
- 따라서 이 사건 도급계약이 2020. 12. 21. 자동해지되었다는 근로자의 주장은 받아들이지 않음.
- 다만, 회사의 이행지체를 이유로 한 근로자의 계약해지 주장은 포함된 것으로 선해하여, 근로자의 계약해지 통지가 회사에게 도달한 2021. 5. 17.경 이 사건 도급계약이 해지되었다고 판단함.
확보한 수집 내용입니다. 전문 여부와 앞뒤 누락, 문단·표·공백의 원형 보존은 확인되지 않았습니다.
공식 원문 미확인
1. 피고는 원고에게 934,159,605원 및 이에 대하여 2023. 11. 1.부터 2024. 6. 20.까지는 연 5%의, 그 다음 날부터 다 갚는 날까지는 연 12%의 각 비율로 계산한 돈을 지급하라. 2. 원고의 나머지 청구를 기각한다. 3. 소송비용 중 1/3은 원고가, 나머지는 피고가 부담하고, 보조참가로 인한 비용은 피고보조참가인이 부담한다. 4. 제1항은 가집행할 수 있다.
{"source_kind": "bigcase_html_noauth", "extraction_method": "next_data_noauth", "ai_summary": "# \uac74\ucd95\uacf5\uc0ac \ub3c4\uae09\uacc4\uc57d \ud574\uc9c0 \ubc0f \ud558\uc790\ubcf4\uc218\uc5d0 \ub530\ub978 \ubd80\ub2f9\uc774\ub4dd, \uc9c0\uccb4\uc0c1\uae08, \uc190\ud574\ubc30\uc0c1 \uccad\uad6c \uc0ac\uac74\n## \uacb0\uacfc \uc694\uc57d\n- \ud53c\uace0\ub294 \uc6d0\uace0\uc5d0\uac8c **934,159,605\uc6d0** \ubc0f \uc774\uc5d0 \ub300\ud55c \uc9c0\uc5f0\uc190\ud574\uae08\uc744 \uc9c0\uae09\ud568.\n- \uc6d0\uace0\uc758 \ub098\uba38\uc9c0 \uccad\uad6c\ub294 \uae30\uac01\ud568.\n- \uc18c\uc1a1\ube44\uc6a9\uc740 \uc6d0\uace0\uac00 1/3, \ud53c\uace0\uac00 2/3 \ubd80\ub2f4\ud558\uace0, \ubcf4\uc870\ucc38\uac00\ub85c \uc778\ud55c \ube44\uc6a9\uc740 \ud53c\uace0\ubcf4\uc870\ucc38\uac00\uc778\uc774 \ubd80\ub2f4\ud568.\n## \uc0ac\uc2e4\uad00\uacc4\n- \uc6d0\uace0\ub294 2020. 6. 24. \ud53c\uace0\uc5d0\uac8c '(\uc8fc)A \uacf5\uc7a5 \uc99d\ucd95\uacf5\uc0ac'\ub97c \ub3c4\uae09\ud558\uc600\uace0, 2020. 12. 4. \uc900\uacf5\uae30\ud55c\uc744 2020. 12. 20.\ub85c \uc5f0\uc7a5\ud558\ub294 \ubcc0\uacbd\uacc4\uc57d\uc744 \uccb4\uacb0\ud568.\n- \ud53c\uace0\ub294 2020. 10. 20. \ud53c\uace0\ubcf4\uc870\ucc38\uac00\uc778\uc5d0\uac8c \uc774 \uc0ac\uac74 \uacf5\uc0ac \uc911 \ud310\ub12c, \ucc3d\ud638, \uc720\ub9ac\uacf5\uc0ac \ubd80\ubd84\uc744 \ud558\ub3c4\uae09\ud558\uc600\uace0, \ud53c\uace0\ubcf4\uc870\ucc38\uac00\uc778\uc740 2020. 11. 5. \uc774 \uc0ac\uac74 \uc0cc\ub4dc\uc704\uce58\ud310\ub12c \uc124\uce58\uacf5\uc0ac\ub97c \uc644\ub8cc\ud568.\n- \uc6d0\uace0\ub294 2021. 2. 15. \uc774\ud6c4 \ud53c\uace0\uc5d0\uac8c \uae30\uc131\uace0 \uacf5\uc0ac\ub300\uae08\uc744 \uc9c0\uae09\ud558\uc9c0 \uc54a\uc558\uace0, 2021. 2.\uacbd \ud53c\uace0\uc640 \uc8fc\uc694 \uacf5\uc0ac\ub300\uae08\uc744 \ud558\ub3c4\uae09\uc5c5\uccb4\uc5d0 \uc9c1\uc811 \uc9c0\uae09\ud558\uae30\ub85c \ud569\uc758\ud568.\n- \ud53c\uace0\ub294 2021. 5.\uacbd\uae4c\uc9c0 \uc678\ubd80\ud310\ub12c \ub9c8\uac10\uacf5\uc0ac \ub4f1\uc744 \uc9c4\ud589\ud558\ub2e4\uac00 \uacf5\uc0ac\ub97c \uc911\ub2e8\ud558\uc600\uace0, \uc6d0\uace0\ub294 \ud604\uc7ac\uae4c\uc9c0 \uc2e0\ucd95 \uacf5\uc7a5 \uac74\ubb3c\uc5d0 \ub300\ud55c \uc0ac\uc6a9\uc2b9\uc778\uc744 \ubc1b\uc9c0 \ubabb\ud568.\n- \uc6d0\uace0\ub294 2021. 6. 7.\uacbd\uae4c\uc9c0 \ud53c\uace0 \ub610\ub294 \ud558\ub3c4\uae09\uc5c5\uccb4\uc5d0 \ucd1d 1,569,463,420\uc6d0\uc744 \uc9c0\uae09\ud568.\n## \ud575\uc2ec \uc7c1\uc810, \ubc95\ub9ac \ubc0f \ubc95\uc6d0\uc758 \ud310\ub2e8\n### \uc774 \uc0ac\uac74 \ub3c4\uae09\uacc4\uc57d\uc758 \ud574\uc9c0 \uc5ec\ubd80 \ubc0f \uc2dc\uc810\n- **\ubc95\ub9ac**: \uc30d\ubb34\uacc4\uc57d\uc5d0\uc11c \uc790\ub3d9\ud574\uc81c \uc57d\uc815\uc774 \uc788\ub354\ub77c\ub3c4, \ub2f9\uc0ac\uc790\ub4e4\uc774 \uacc4\uc57d\uc774 \uc720\ud6a8\ud568\uc744 \uc804\uc81c\ub85c \uc774\ud589\uc744 \ucd09\uad6c\ud558\uac70\ub098 \uae09\ubd80\ub97c \uc218\ub839\ud558\uc600\ub2e4\uba74 \uc790\ub3d9\ud574\uc81c \uc57d\uc815\uc758 \ud6a8\ub825\uc744 \uc0c1\uc2e4\uc2dc\ud0a4\uace0 \uacc4\uc57d\uc744 \ubd80\ud65c\uc2dc\ud0a4\uae30\ub85c \ud569\uc758\ud55c \uac83\uc73c\ub85c \ubd04\uc774 \uc0c1\ub2f9\ud568. \uc774 \uacbd\uc6b0 \ucc44\ubb34\ubd88\uc774\ud589\uc744 \uc774\uc720\ub85c \ud55c \ud574\uc81c\uad8c \ud589\uc0ac\ub294 \ubcc4\ub3c4\uc758 \ucd5c\uace0\ub97c \uc694\ud558\uc9c0 \uc54a\uc74c.\n- **\ud310\ub2e8**:\n- \uc6d0\uace0\uc640 \ud53c\uace0\ub294 \uc774 \uc0ac\uac74 \uacf5\uc0ac\uc758 \uc900\uacf5\uae30\ud55c\uc744 2020. 12. 20.\ub85c \uc815\ud558\uc600\uace0, \uacf5\uc0ac\uacc4\uc57d \ud2b9\uc218\uc870\uac74 \uc81c4\uc870\uc5d0 \ub530\ub77c \uc900\uacf5\uae30\ud55c \ub0b4 \ubbf8\uc900\uacf5 \uc2dc \uacc4\uc57d\uc774 \uc790\ub3d9\ud574\uc9c0\ub41c\ub2e4\uace0 \uc57d\uc815\ud568.\n- \uadf8\ub7ec\ub098 \uc6d0\uace0\uac00 2021. 2.\uacbd \ud558\ub3c4\uae09\uc5c5\uccb4\uc5d0 \uc9c1\uc811 \uacf5\uc0ac\ub300\uae08\uc744 \uc9c0\uae09\ud558\uae30\ub85c \ud569\uc758\ud558\uace0 2021. 5.\uacbd\uae4c\uc9c0 \uacf5\uc0ac\uac00 \uc9c4\ud589\ub41c \uc810, \uc6d0\uace0\uac00 2021. 3. 29. \ubc0f 2021. 4. 23. \ud53c\uace0\uc5d0\uac8c \uc9c0\uccb4\uc0c1\uae08 \uc9c0\uae09\uc744 \uc694\uccad\ud558\uba70 \uc774\ud589\uc744 \ucd09\uad6c\ud55c \uc810 \ub4f1\uc744 \uace0\ub824\ud560 \ub54c, \uc790\ub3d9\ud574\uc81c \uc57d\uc815\uc758 \ud6a8\ub825\uc744 \uc0c1\uc2e4\uc2dc\ud0a4\uace0 \uacc4\uc57d\uc744 \ubd80\ud65c\uc2dc\ud0a4\uae30\ub85c \ud569\uc758\ud55c \uac83\uc73c\ub85c \ubd04\uc774 \uc0c1\ub2f9\ud568.\n- \ub530\ub77c\uc11c \uc774 \uc0ac\uac74 \ub3c4\uae09\uacc4\uc57d\uc774 2020. 12. 21. \uc790\ub3d9\ud574\uc9c0\ub418\uc5c8\ub2e4\ub294 \uc6d0\uace0\uc758 \uc8fc\uc7a5\uc740 \ubc1b\uc544\ub4e4\uc774\uc9c0 \uc54a\uc74c.\n- \ub2e4\ub9cc, \ud53c\uace0\uc758 \uc774\ud589\uc9c0\uccb4\ub97c \uc774\uc720\ub85c \ud55c \uc6d0\uace0\uc758 \uacc4\uc57d\ud574\uc9c0 \uc8fc\uc7a5\uc740 \ud3ec\ud568\ub41c \uac83\uc73c\ub85c \uc120\ud574\ud558\uc5ec, \uc6d0\uace0\uc758 \uacc4\uc57d\ud574\uc9c0 \ud1b5\uc9c0\uac00 \ud53c\uace0\uc5d0\uac8c \ub3c4\ub2ec\ud55c **2021. 5. 17.\uacbd** \uc774 \uc0ac\uac74 \ub3c4\uae09\uacc4\uc57d\uc774 \ud574\uc9c0\ub418\uc5c8\ub2e4\uace0 \ud310\ub2e8\ud568.\n- \ud53c\uace0\uc758 \uc900\uacf5\uae30\ud55c \uc5f0\uc7a5 \uc8fc\uc7a5\uc740, \ubcc0\uacbd\uacc4\uc57d\uc11c\uc758 \uc218\uc815 \ubc29\uc2dd, \uac74\ucd95\uc8fc\uc758 \uc11c\uba85 \ubd80\uc7ac, \uc6d0\uace0\uc758 \uc9c0\uccb4\uc0c1\uae08 \uc694\uad6c\uc5d0 \ub300\ud55c \ud53c\uace0\uc758 \uc774\uc758 \uc81c\uae30 \uc5c6\uc74c, \ubd88\uac00\ud56d\ub825 \uc0ac\uc720\uc5d0 \ub300\ud55c \uc5f0\uc7a5 \uc694\uccad \ubd80\uc7ac \ub4f1\uc744 \uc885\ud569\ud558\uc5ec \uc778\uc815\ud558\uae30 \uc5b4\ub824\uc6c0.\n- \ud53c\uace0\uc758 \uc790\ub3d9\ud574\uc81c \uc870\ud56d \ubb34\ud6a8 \uc8fc\uc7a5\uc740, \uc774 \uc0ac\uac74 \ub3c4\uae09\uacc4\uc57d\uc774 \uc790\ub3d9\ud574\uc9c0\ub41c \uac83\uc774 \uc544\ub2c8\ub77c \uc774\ud589\uc9c0\uccb4\ub97c \uc774\uc720\ub85c \ud574\uc9c0\ub41c \uac83\uc73c\ub85c \ud310\ub2e8\ud558\uc600\uc73c\ubbc0\ub85c \uc774\uc720 \uc5c6\uc74c.\n#### \uad00\ub828 \ud310\ub840 \ubc0f \ubc95\ub839\n- \ub300\ubc95\uc6d0 1992. 10. 27. \uc120\uace0 91\ub2e4483 \ud310\uacb0\n- \ub300\ubc95\uc6d0 2003. 1. 24. \uc120\uace0 2000\ub2e45336, 5343 \ud310\uacb0\n- \ub300\ubc95\uc6d0 2019. 6. 27. \uc120\uace0 2019\ub2e4216817 \ud310\uacb0\n### \ubd80\ub2f9\uc774\ub4dd\ubc18\ud658\uccad\uad6c\n- **\ubc95\ub9ac**: \uac74\ucd95\uacf5\uc0ac\ub3c4\uae09\uacc4\uc57d\uc774 \uc218\uae09\uc778\uc758 \ucc44\ubb34\ubd88\uc774\ud589\uc73c\ub85c \ud574\uc81c\ub41c \uacbd\uc6b0, \uacf5\uc0ac\uac00 \uc0c1\ub2f9\ud55c \uc815\ub3c4\ub85c \uc9c4\ucc99\ub418\uc5b4 \uc6d0\uc0c1\ud68c\ubcf5\uc774 \uc911\ub300\ud55c \uc0ac\ud68c\uc801\u00b7\uacbd\uc81c\uc801 \uc190\uc2e4\uc744 \ucd08\ub798\ud558\uace0 \uc644\uc131\ub41c \ubd80\ubd84\uc774 \ub3c4\uae09\uc778\uc5d0\uac8c \uc774\uc775\uc774 \ub418\ub294 \uacbd\uc6b0, \ub3c4\uae09\uacc4\uc57d\uc740 \ubbf8\uc644\uc131 \ubd80\ubd84\uc5d0 \ub300\ud574\uc11c\ub9cc \uc2e4\ud6a8\ub418\uace0 \uc218\uae09\uc778\uc740 \ud574\uc81c \uc0c1\ud0dc \uadf8\ub300\ub85c \uac74\ubb3c\uc744 \ub3c4\uae09\uc778\uc5d0\uac8c \uc778\ub3c4\ud558\uba70, \ub3c4\uae09\uc778\uc740 \uc778\ub3c4\ubc1b\uc740 \ubbf8\uc644\uc131 \uac74\ubb3c\uc5d0 \ub300\ud55c \ubcf4\uc218\ub97c \uc9c0\uae09\ud574\uc57c \ud568. \uc774\ub54c \ubcf4\uc218\ub294 \uc57d\uc815\ud55c \ucd1d \uacf5\uc0ac\ube44\uc5d0 \uae30\uc131\uace0 \ube44\uc728\uc744 \uc801\uc6a9\ud55c \uae08\uc561\uc73c\ub85c \uc0b0\uc815\ud568. \uae30\uc131\uace0 \ube44\uc728\uc740 \uacf5\uc0ac \uc911\ub2e8 \ub2f9\uc2dc\ub97c \uae30\uc900\uc73c\ub85c \uc644\uc131\ub41c \ubd80\ubd84\uc5d0 \ub4e4\uc5b4\uac04 \uacf5\uc0ac\ube44\uc640 \ubbf8\uc2dc\uacf5 \ubd80\ubd84\uc744 \uc644\uc131\ud558\ub294 \ub370 \ub4e4\uc5b4\uac08 \uacf5\uc0ac\ube44\ub97c \ud569\uce5c \uc804\uccb4 \uacf5\uc0ac\ube44 \uc911 \uc644\uc131\ub41c \ubd80\ubd84\uc5d0 \ub4e4\uc5b4\uac04 \ube44\uc6a9\uc774 \ucc28\uc9c0\ud558\ub294 \ube44\uc728\ub85c \ud655\uc815\ud568.\n- **\ud310\ub2e8**:\n- \uc774 \uc0ac\uac74 \uacf5\uc0ac\uc758 \ucd1d \uacf5\uc0ac\ub300\uae08\uc740 1,980,000,000\uc6d0\uc774\uace0, \uc6d0\uace0\uac00 \ud53c\uace0\uc5d0\uac8c \uc9c0\uae09\ud55c \uae30\uc2dc\uacf5 \uacf5\uc0ac\ube44\ub294 1,569,463,420\uc6d0, \ubbf8\uc2dc\uacf5 \ubd80\ubd84 \uc644\uc131\uc5d0 \ub4e4\uc5b4\uac08 \uacf5\uc0ac\ube44\ub294 530,647,300\uc6d0\uc784.\n- \uc704 \ubc95\ub9ac\uc5d0 \ub530\ub77c \uc6d0\uace0\uac00 \ud53c\uace0\uc5d0\uac8c \uc9c0\uae09\ud574\uc57c \ud560 \uae30\uc131\uace0 \uacf5\uc0ac\ub300\uae08\uc740 1,479,701,780\uc6d0\uc784.\n- \ub530\ub77c\uc11c \ud53c\uace0\ub294 \uc6d0\uace0\uc5d0\uac8c \uae30\uc131\uace0 \uacf5\uc0ac\ub300\uae08\uc744 \ucd08\uacfc\ud558\uc5ec \uc9c0\uae09\ubc1b\uc740 **89,761,640\uc6d0**\uc744 \ubd80\ub2f9\uc774\ub4dd\uc73c\ub85c \ubc18\ud658\ud560 \uc758\ubb34\uac00 \uc788\uc74c.\n- \ud53c\uace0\uc758 \uc794\uc5ec\uacf5\uc0ac\ub0b4\uc5ed\uc11c \ubc0f \uacf5\uc0ac\uc6d0\uac00\uacc4\uc0b0\uc11c\uc758 \uae08\uc561\uc774 \uc7ac\uc2dc\uacf5 \ubc0f \ucd94\uac00\uacf5\uc0ac \ud3ec\ud568 \uae08\uc561\uc774\ub77c\ub294 \uc8fc\uc7a5\uc740, \uc6d0\uace0\uc640 \ud53c\uace0\uac00 \uc815\uc0b0\uc744 \ud1b5\uc9c0\ud558\uace0 \ud53c\uace0\uac00 \uc794\uc5ec\uacf5\uc0ac\ub0b4\uc5ed\uc11c\ub97c \uc804\ub2ec\ud588\uc73c\uba70, \ub0b4\uc5ed\uc11c\uc5d0 '\ubbf8\uc2dc\uacf5\ub41c \ubd80\ubd84'\uc774\ub77c\ub294 \uba85\uc2dc\uc801 \uae30\uc7ac\uc640 \ub2f4\ub2f9\uc790 \uc11c\uba85\uc774 \uc788\ub294 \uc810 \ub4f1\uc744 \uace0\ub824\ud560 \ub54c \ubc1b\uc544\ub4e4\uc774\uc9c0 \uc54a\uc74c.\n- \ud53c\uace0\uc758 \ubcf5\ud569\ud310\ub12c \ubc0f \ub9ac\uc5bc\uc9d5\ud06c\uac15\ud310 \uad00\ub828 \uacf5\uc0ac\ube44\uac00 \uc774 \uc0ac\uac74 \uacf5\uc0ac \ubc94\uc704\uc5d0 \ud3ec\ud568\ub418\uc9c0 \uc54a\ub294\ub2e4\ub294 \uc8fc\uc7a5\uc740, \ud574\ub2f9 \uacf5\uc0ac\uac00 \uc774 \uc0ac\uac74 \uacf5\uc0ac\uc758 \uc8fc\ub41c \ubd80\ubd84\uacfc \uad00\ub828\ub418\uace0, \ub204\uc218 \ubc29\uc9c0 \ub4f1\uc744 \uc704\ud55c \ucd94\uac00 \uacf5\uc0ac \ud544\uc694\uc131\uc774 \uc788\uc5c8\uc73c\uba70, \uc138\uae08\uacc4\uc0b0\uc11c \uc0c1\ub300\ubc29\uc774 \ud53c\uace0\uc600\uace0 \ud53c\uace0\uac00 \uc9c1\uc811 \uc9c0\uae09\uc5d0 \ub3d9\uc758\ud55c \uc810 \ub4f1\uc744 \uace0\ub824\ud560 \ub54c \ubc1b\uc544\ub4e4\uc774\uc9c0 \uc54a\uc74c.\n#### \uad00\ub828 \ud310\ub840 \ubc0f \ubc95\ub839\n- \ub300\ubc95\uc6d0 1992. 3. 31. \uc120\uace0 91\ub2e442630 \ud310\uacb0\n- \ub300\ubc95\uc6d0 1993. 11. 23. \uc120\uace0 93\ub2e425080 \ud310\uacb0\n- \ub300\ubc95\uc6d0 1989. 12. 26. \uc120\uace0 88\ub2e4\uce7432470, 32487 \ud310\uacb0\n- \ub300\ubc95\uc6d0 1996. 1. 23. \uc120\uace0 94\ub2e431631, 31648 \ud310\uacb0\n### \uc9c0\uccb4\uc0c1\uae08\uccad\uad6c\n- **\ubc95\ub9ac**: \uc218\uae09\uc778\uc774 \ucc45\uc784\uc9c8 \uc218 \uc5c6\ub294 \uc0ac\uc720\ub85c \uacf5\uc0ac\uac00 \uc9c0\uc5f0\ub41c \uacbd\uc6b0 \uadf8 \uae30\uac04\ub9cc\ud07c \uc9c0\uccb4\uc77c\uc218\uc5d0\uc11c \uc81c\uc678\ub418\uc5b4\uc57c \ud558\ub098, \uc774\ub294 \uacf5\uc0ac\ub3c4\uae09\uacc4\uc57d\uc5d0\uc11c \uc608\uc0c1\uce58 \ubabb\ud55c \uc0ac\uc815\uc774 \ubc1c\uc0dd\ud558\uc5ec \uacf5\uc0ac \uc9c0\uc5f0\uc774 \ubd88\uac00\ud53c\ud588\uc74c\uc744 \uc785\uc99d\ud574\uc57c \ud568. \uc9c0\uccb4\uc0c1\uae08\uc740 \uc57d\uc815 \uc900\uacf5\uc77c \ub2e4\uc74c\ub0a0\ubd80\ud130 \ubc1c\uc0dd\ud558\ub418, \uadf8 \uc885\uae30\ub294 \uc218\uae09\uc778\uc774 \uacf5\uc0ac\ub97c \uc911\ub2e8\ud558\uac70\ub098 \ud574\uc81c\uc0ac\uc720\uac00 \uc788\uc5b4 \ub3c4\uae09\uc778\uc774 \uacc4\uc57d\uc744 \ud574\uc81c\ud560 \uc218 \uc788\uc5c8\uc744 \ub54c\ubd80\ud130 \ub3c4\uae09\uc778\uc774 \ub2e4\ub978 \uc5c5\uc790\uc5d0\uac8c \ub9e1\uaca8 \uacf5\uc0ac\ub97c \uc644\uc131\ud560 \uc218 \uc788\uc5c8\ub358 \uc2dc\uc810\uae4c\uc9c0\uc784. \ubc95\uc6d0\uc740 \ubbfc\ubc95 \uc81c398\uc870 \uc81c2\ud56d\uc5d0 \ub530\ub77c \uc57d\uc815 \uc9c0\uccb4\uc0c1\uae08\uc561\uc774 \ubd80\ub2f9\ud558\uac8c \uacfc\ub2e4\ud558\ub2e4\uace0 \uc778\uc815\ud558\ub294 \uacbd\uc6b0 \uc774\ub97c \uc801\ub2f9\ud788 \uac10\uc561\ud560 \uc218 \uc788\uc74c.\n- **\ud310\ub2e8**:\n- \uc774 \uc0ac\uac74 \uacf5\uc0ac\uc758 \uc900\uacf5\uae30\ud55c\uc740 2020. 12. 20.\uc774\uace0, \ud53c\uace0\ub294 \uae30\ud55c \ub0b4 \uacf5\uc0ac\ub97c \uc644\uc131\ud558\uc9c0 \ubabb\ud558\uace0 \uc911\ub2e8\ud558\uc600\uc73c\uba70, \uc9c0\uccb4\uc0c1\uae08\uc728\uc740 3/1000\uc784. \ub530\ub77c\uc11c \ud53c\uace0\ub294 \uc6d0\uace0\uc5d0\uac8c \uc9c0\uccb4\uc0c1\uae08\uc744 \uc9c0\uae09\ud560 \uc758\ubb34\uac00 \uc788\uc74c.\n- \ud53c\uace0\uc758 \uc900\uacf5\uae30\ud55c \uc5f0\uc7a5 \ubc0f \ucc45\uc784 \uc5c6\ub294 \uc0ac\uc720\ub85c \uc778\ud55c \uacf5\uc0ac \uc911\ub2e8 \uc8fc\uc7a5\uc740 \uc778\uc815\ud558\uae30 \uc5b4\ub824\uc6c0.\n- \uc6d0\uace0\uac00 \uc774 \uc0ac\uac74 \ub3c4\uae09\uacc4\uc57d\uc744 \ud574\uc81c\ud560 \uc218 \uc788\uc5c8\ub358 \uc2dc\uc810\uc740 \uacf5\uc0ac\uacc4\uc57d \ud2b9\uc218\uc870\uac74 \uc81c4\uc870\uc5d0 \uadfc\uac70\ud558\uc5ec \uc790\ub3d9\ud574\uc9c0\ub97c \uc8fc\uc7a5\ud560 \uc218 \uc788\uc5c8\ub358 **2020. 12. 21.**\ub85c \ubd04\uc774 \uc0c1\ub2f9\ud568.\n- \ubbf8\uc2dc\uacf5 \uacf5\uc0ac\ub97c \uc644\uc131\ud558\ub294 \ub370 \ud544\uc694\ud55c \uae30\uac04\uc740 \uac10\uc815 \uacb0\uacfc\ub97c \ucc38\uc791\ud558\uc5ec **105\uc77c**\ub85c \uc778\uc815\ud568.\n- \uc774\uc5d0 \ub530\ub978 \uc9c0\uccb4\uc0c1\uae08\uc740 623,700,000\uc6d0\uc784.\n- \uadf8\ub7ec\ub098 \uc774 \uc0ac\uac74 \uacf5\uc0ac\uc758 \ub0b4\uc6a9\uacfc \ubaa9\uc801, \uc900\uacf5\uae30\ud55c, \uc9c0\uccb4\uc0c1\uae08\uc728\uc758 \ube44\uad50\uc801 \ub192\uc74c, \uc9c0\uccb4\uc0c1\uae08 \ubc1c\uc0dd \uae30\uac04\uc758 \uc7a5\uae30\uc131, \uad11\uc8fc \uc9c0\uc5ed\uc758 \uc7a5\ub9c8 \ub4f1 \uc608\uc0c1\uce58 \ubabb\ud55c \uacf5\uc0ac \uc9c0\uc5f0 \uc0ac\uc720 \uac00\ub2a5\uc131, \ud53c\uace0\uac00 \uc9c0\uae09\ud574\uc57c \ud560 \ucd1d \uae08\uc561 \ub4f1\uc744 \uc885\ud569\uc801\uc73c\ub85c \uace0\ub824\ud560 \ub54c, \uc704 \uc9c0\uccb4\uc0c1\uae08\uc561\uc740 \ubd80\ub2f9\ud558\uac8c \uacfc\ub2e4\ud558\ub2e4\uace0 \ud310\ub2e8\ud558\uc5ec **50% \uac10\uc561**\ud568.\n- \ub530\ub77c\uc11c \ud53c\uace0\ub294 \uc6d0\uace0\uc5d0\uac8c **311,850,000\uc6d0**\uc758 \uc9c0\uccb4\uc0c1\uae08\uc744 \uc9c0\uae09\ud560 \uc758\ubb34\uac00 \uc788\uc74c.\n#### \uad00\ub828 \ud310\ub840 \ubc0f \ubc95\ub839\n- \ub300\ubc95\uc6d0 2005. 11. 25. \uc120\uace0 2003\ub2e460136 \ud310\uacb0\n- \ub300\ubc95\uc6d0 2010. 1. 28. \uc120\uace0 2009\ub2e441137, 41144 \ud310\uacb0\n- \ub300\ubc95\uc6d0 1999. 10. 12. \uc120\uace0 99\ub2e414846 \ud310\uacb0\n- \ub300\ubc95\uc6d0 2002. 9. 4. \uc120\uace0 2001\ub2e41386 \ud310\uacb0\n- \ubbfc\ubc95 \uc81c398\uc870 \uc81c2\ud56d\n### \uc190\ud574\ubc30\uc0c1\uccad\uad6c (\ud558\uc790\ubcf4\uc218\ube44\uc6a9)\n- **\ubc95\ub9ac**: \uac74\ucd95\ubb3c\uc758 \ud558\uc790\ub294 \uacf5\uc0ac\uacc4\uc57d \ub0b4\uc6a9\uacfc \ub2e4\ub978 \uad6c\uc870\uc801\u00b7\uae30\ub2a5\uc801 \uacb0\ud568\uc774 \uc788\uac70\ub098, \uac70\ub798\uad00\ub150\uc0c1 \ud1b5\uc0c1 \uac16\ucd94\uc5b4\uc57c \ud560 \ud488\uc9c8\uc744 \uac16\ucd94\uc9c0 \ubabb\ud55c \uac83\uc744 \uc758\ubbf8\ud568. \ud558\uc790 \uc5ec\ubd80\ub294 \uacc4\uc57d \ub0b4\uc6a9, \uc124\uacc4\ub3c4 \ubd80\ud569 \uc5ec\ubd80, \uac74\ucd95 \uad00\ub828 \ubc95\ub839 \uae30\uc900 \uc801\ud569 \uc5ec\ubd80 \ub4f1\uc744 \uc885\ud569\uc801\uc73c\ub85c \uace0\ub824\ud558\uc5ec \ud310\ub2e8\ud568. \uc900\ubd88\uc5f0\uc7ac\ub8cc \ubc0f \ub09c\uc5f0\uc7ac\ub8cc\ub294 \ud55c\uad6d\uc0b0\uc5c5\uaddc\uaca9 KS F ISO 5660-1\uc5d0 \ub530\ub77c \uac00\uc5f4\uc2dc\ud5d8 \uc2dc \uc720\ud574\ud55c \uade0\uc5f4, \uad6c\uba4d, \uc6a9\uc735 \ub4f1\uc774 \uc5c6\uc5b4\uc57c \ud568.\n- **\ud310\ub2e8**:\n- \uc774 \uc0ac\uac74 \uc0cc\ub4dc\uc704\uce58\ud310\ub12c\uc740 \uacf5\uc0ac\uc6d0\uac00\uacc4\uc57d\uc11c\uc5d0 '\uc0cc\ub4dc\uc704\uce58\ud310\ub12c(\ub09c\uc5f03\uae09)'\uc73c\ub85c \uae30\uc7ac\ub418\uc5b4 \ub09c\uc5f0\uc7ac\ub8cc \ub610\ub294 \uc900\ubd88\uc5f0\uc7ac\ub8cc \uae30\uc900\uc744 \ucda9\uc871\ud574\uc57c \ud568.\n- F\uc5f0\uad6c\uc6d0\uc758 \uc2dc\ud5d8 \uacb0\uacfc, \uad11\uc8fc\uad11\uc5ed\uc2dc \ubd81\uad6c\uccad\uc758 \uac74\ucd95\uc548\uc804 \ubaa8\ub2c8\ud130\ub9c1 \ud604\uc7a5 \uc810\uac80 \uacb0\uacfc, \uac10\uc815\uc778 E\uc758 \uac10\uc815 \uacb0\uacfc \ubaa8\ub450 \uc774 \uc0ac\uac74 \uc0cc\ub4dc\uc704\uce58\ud310\ub12c\uc774 **\uc900\ubd88\uc5f0\uc7ac\ub8cc \ubd80\uc801\ud569** \ud310\uc815\uc744 \ubc1b\uc74c.\n- \uc774\ub85c \uc778\ud574 \uc6d0\uace0\ub294 \uacf5\uc7a5 \uac74\ubb3c\uc5d0 \ub300\ud55c \uc0ac\uc6a9\uc2b9\uc778\uc744 \ubc1b\uc9c0 \ubabb\ud558\uace0 \uc788\uc73c\ubbc0\ub85c, \uc774 \uc0ac\uac74 \uc0cc\ub4dc\uc704\uce58\ud310\ub12c\uc5d0 \uad6c\uc870\uc801\u00b7\uae30\ub2a5\uc801 \uacb0\ud568\uc774 \uc874\uc7ac\ud55c\ub2e4\uace0 \uc778\uc815\ud568.\n- \ud53c\uace0\ubcf4\uc870\ucc38\uac00\uc778\uc758 \uc2dc\ud5d8\uae30\uc900 \uc801\ud569 \uc8fc\uc7a5 \ubc0f \uc774 \uc0ac\uac74 \uc2dc\ud5d8 \uacb0\uacfc\uc758 \ubb38\uc81c\uc810 \uc8fc\uc7a5\uc740, \ud53c\uace0\ubcf4\uc870\ucc38\uac00\uc778\uc774 \uc81c\ucd9c\ud55c \ub2e4\uc218\uc758 \uc801\ud569 \ud310\uc815 \uae30\ub85d\uc774 \uc774 \uc0ac\uac74 \ud558\ub3c4\uae09\uacf5\uc0ac\uc5d0 \uc0ac\uc6a9\ub41c \uc790\uc7ac\uc640 \ub3d9\uc77c\ud55c\uc9c0 \ud655\uc778\ud560 \uc218 \uc5c6\uace0, \uc774 \uc0ac\uac74 \uc2dc\ud5d8 \ubc29\ubc95 \ubc0f \uacb0\uacfc\uc5d0 \ud2b9\ubcc4\ud55c \ubb38\uc81c\uac00 \uc5c6\uc73c\uba70, \uac10\uc815\uc778\uc758 \uac10\uc815 \uacb0\uacfc\ub3c4 \ub3d9\uc77c\ud55c \uacb0\ub860\uc744 \ub0b4\ub838\ub2e4\ub294 \uc810 \ub4f1\uc744 \uace0\ub824\ud560 \ub54c \ubc1b\uc544\ub4e4\uc774\uc9c0 \uc54a\uc74c.\n- \ud53c\uace0\ub294 \uc774 \uc0ac\uac74 \uc0cc\ub4dc\uc704\uce58\ud310\ub12c\uc758 \ud558\uc790\ub85c \uc778\ud574 \uc6d0\uace0\uc5d0\uac8c \ud558\uc790 \ubcf4\uc218\ube44\uc6a9 \uc0c1\ub2f9\uc758 \uc190\ud574\ub97c \ubc30\uc0c1\ud560 \ucc45\uc784\uc774 \uc788\uc74c.\n- \ud53c\uace0\ubcf4\uc870\ucc38\uac00\uc778\uc758 \ud558\uc790\ub2f4\ubcf4\ucc45\uc784\uae30\uac04 \uacbd\uacfc \uc8fc\uc7a5\uc740, \uc6d0\uace0\uac00 \ubbfc\ubc95 \uc81c390\uc870\uc5d0 \ub530\ub978 \ucc44\ubb34\ubd88\uc774\ud589\uc73c\ub85c \uc778\ud55c \uc190\ud574\ubc30\uc0c1\uc744 \uccad\uad6c\ud558\ub294 \uac83\uc774\ubbc0\ub85c \uc774\uc720 \uc5c6\uc74c.\n- \uac10\uc815 \uacb0\uacfc\uc5d0 \ub530\ub77c \uae30\uc874 \uc0cc\ub4dc\uc704\uce58\ud310\ub12c\uc744 \ucca0\uac70\ud558\uace0 \uc801\ud569\ud55c \uc7ac\ub8cc\ub85c \uc7ac\uc2dc\uacf5\ud558\ub294 \ub370 \uc18c\uc694\ub418\ub294 \uacf5\uc0ac\ube44\ub294 **532,547,965\uc6d0**\uc784.\n- \uc6d0\uace0\uc758 \uac10\uc815\uacb0\uacfc \uc81c1\uc548\uc5d0 \ub530\ub978 \uc190\ud574\ubc30\uc0c1\uc561 \uc8fc\uc7a5\uc740, \uc81c1\uc548\uc774 \ucd94\uac00 \uacf5\uc0ac \ube44\uc6a9\uc744 \ud3ec\ud568\ud558\uace0 \uc788\uc5b4 \uc801\ud569\ud55c \uc0cc\ub4dc\uc704\uce58\ud310\ub12c \uc2dc\uacf5 \uc2dc \ubd88\ud544\uc694\ud558\ub2e4\uace0 \ud310\ub2e8\ub418\ubbc0\ub85c \ubc1b\uc544\ub4e4\uc774\uc9c0 \uc54a\uc74c.\n- \ub530\ub77c\uc11c \ud53c\uace0\ub294 \uc6d0\uace0\uc5d0\uac8c **532,547,965\uc6d0**\uc744 \uc190\ud574\ubc30\uc0c1\uc73c\ub85c \uc9c0\uae09\ud560 \uc758\ubb34\uac00 \uc788\uc74c.\n#### \uad00\ub828 \ud310\ub840 \ubc0f \ubc95\ub839\n- \ub300\ubc95\uc6d0 2010. 12. 9. \uc120\uace0 2008\ub2e416851 \ud310\uacb0\n- \uac74\ucd95\ubb3c \ub9c8\uac10\uc7ac\ub8cc\uc758 \ub09c\uc5f0\uc131\ub2a5 \ubc0f \ud654\uc7ac \ud655\uc0b0 \ubc29\uc9c0\uad6c\uc870 \uae30\uc900(\uad6d\ud1a0\uad50\ud1b5\ubd80\uace0\uc2dc \uc81c2020-263\ud638, \uc2dc\ud589 2020. 3. 13.) \uc81c3, 4, 5\uc870 \uc81c2\ud56d, 6\uc870 \uc81c2\ud56d\n- \ud55c\uad6d\uc0b0\uc5c5\uaddc\uaca9 KS F ISO 5660-1\n- \ub300\ubc95\uc6d0 2020. 6. 11. \uc120\uace0 2020\ub2e4201156 \ud310\uacb0\n- \ubbfc\ubc95 \uc81c390\uc870\n- \ub300\ubc95\uc6d0 2012. 1. 12. \uc120\uace0 2009\ub2e484608 \ud310\uacb0\n## \uac80\ud1a0\n- \ubcf8 \ud310\uacb0\uc740 \uac74\ucd95\uacf5\uc0ac \ub3c4\uae09\uacc4\uc57d \ud574\uc81c \uc2dc \uc790\ub3d9\ud574\uc81c \uc57d\uc815\uc758 \ud6a8\ub825 \uc0c1\uc2e4 \ubc0f \uacc4\uc57d \ubd80\ud65c \ud569\uc758 \uc778\uc815 \uc5ec\ubd80, \uae30\uc131\uace0 \uacf5\uc0ac\ub300\uae08 \uc0b0\uc815 \ubc29\uc2dd, \uc9c0\uccb4\uc0c1\uae08 \uac10\uc561, \uadf8\ub9ac\uace0 \uac74\ucd95\uc790\uc7ac \ud558\uc790\ub85c \uc778\ud55c \uc190\ud574\ubc30\uc0c1 \ucc45\uc784 \uc778\uc815 \ubc0f \ubc94\uc704 \uc0b0\uc815\uc5d0 \ub300\ud55c \uad6c\uccb4\uc801\uc778 \ud310\ub2e8 \uae30\uc900\uc744 \uc81c\uc2dc\ud568.\n- \ud2b9\ud788, \uc790\ub3d9\ud574\uc81c \uc57d\uc815\uc758 \uacbd\uc6b0\uc5d0\ub3c4 \ub2f9\uc0ac\uc790\ub4e4\uc758 \uc0ac\ud6c4 \ud589\ud0dc\uc5d0 \ub530\ub77c \uadf8 \ud6a8\ub825\uc774 \uc0c1\uc2e4\ub420 \uc218 \uc788\uc74c\uc744 \uba85\ud655\ud788 \ud558\uc600\uace0, \uc9c0\uccb4\uc0c1\uae08\uc758 \uacbd\uc6b0 \uc57d\uc815\ub41c \uae08\uc561\uc774\ub77c\ub3c4 \uc5ec\ub7ec \uc0ac\uc815\uc744 \uace0\ub824\ud558\uc5ec \uac10\uc561\ub420 \uc218 \uc788\uc74c\uc744 \uc7ac\ud655\uc778\ud568.\n- \uac74\ucd95\uc790\uc7ac\uc758 \ud558\uc790 \ud310\ub2e8\uc5d0 \uc788\uc5b4\uc11c\ub294 \uacf5\uc778\uae30\uad00 \uc2dc\ud5d8 \uacb0\uacfc, \ud604\uc7a5 \uc810\uac80 \uacb0\uacfc, \uac10\uc815\uc778\uc758 \uac10\uc815 \uacb0\uacfc \ub4f1\uc744 \uc885\ud569\uc801\uc73c\ub85c \uace0\ub824\ud558\uc5ec \ud558\uc790\ub97c \uc778\uc815\ud558\uace0, \ud558\uc790\ubcf4\uc218\ube44\uc6a9 \uc0b0\uc815 \uc2dc \ubd88\ud544\uc694\ud55c \ucd94\uac00 \uacf5\uc0ac \ube44\uc6a9\uc740 \uc81c\uc678\ud574\uc57c \ud568\uc744 \uba85\uc2dc\ud568.\n- \uc774\ub294 \uac74\ucd95\uacf5\uc0ac \uad00\ub828 \ubd84\uc7c1\uc5d0\uc11c \uacc4\uc57d \ud574\uc81c, \uae30\uc131\uace0 \uc815\uc0b0, \uc9c0\uccb4\uc0c1\uae08, \ud558\uc790\ubcf4\uc218 \ub4f1 \ub2e4\uc591\ud55c \uc7c1\uc810\uc5d0 \ub300\ud55c \uc2e4\ubb34\uc801 \ud310\ub2e8 \uae30\uc900\uc744 \uc81c\uacf5\ud558\ub294 \uc911\uc694\ud55c \ud310\ub840\ub85c \ud65c\uc6a9\ub420 \uc218 \uc788\uc74c."}
- 회사의 준공기한 연장 주장은, 변경계약서의 수정 방식, 건축주의 서명 부재, 근로자의 지체상금 요구에 대한 회사의 이의 제기 없음, 불가항력 사유에 대한 연장 요청 부재 등을 종합하여 인정하기 어려움.
- 회사의 자동해제 조항 무효 주장은, 이 사건 도급계약이 자동해지된 것이 아니라 이행지체를 이유로 해지된 것으로 판단하였으므로 이유 없음.
관련 판례 및 법령
- 대법원 1992. 10. 27. 선고 91다483 판결
- 대법원 2003. 1. 24. 선고 2000다5336, 5343 판결
- 대법원 2019. 6. 27. 선고 2019다216817 판결
부당이득반환청구
- 법리: 건축공사도급계약이 수급인의 채무불이행으로 해제된 경우, 공사가 상당한 정도로 진척되어 원상회복이 중대한 사회적·경제적 손실을 초래하고 완성된 부분이 도급인에게 이익이 되는 경우, 도급계약은 미완성 부분에 대해서만 실효되고 수급인은 해제 상태 그대로 건물을 도급인에게 인도하며, 도급인은 인도받은 미완성 건물에 대한 보수를 지급해야 함. 이때 보수는 약정한 총 공사비에 기성고 비율을 적용한 금액으로 산정함. 기성고 비율은 공사 중단 당시를 기준으로 완성된 부분에 들어간 공사비와 미시공 부분을 완성하는 데 들어갈 공사비를 합친 전체 공사비 중 완성된 부분에 들어간 비용이 차지하는 비율로 확정함.
-